Works include WC upgrades, accessibility improvements, storage works, door automation, and resurfacing works at St Brigid’s Community Centre, Ballintra, Co. Donegal.
Deadline
The time limit for receipt of tenders was 2026-02-27.
The procurement was published on 2026-02-02.
Contract notice (2026-02-02) Object Scope of the procurement
Title: Facility Upgrade Works – St Brigid’s Community Centre
Short description:
“Works include WC upgrades, accessibility improvements, storage works, door automation, and resurfacing works at St Brigid’s Community Centre, Ballintra, Co. Donegal.”
Short description
Works include WC upgrades, accessibility improvements, storage works, door automation, and resurfacing works at St Brigid’s Community Centre, Ballintra, Co. Donegal.
Show more
Type of contract: Works
Products/services: Building completion work📦
Estimated value excluding VAT: 80 000 EUR 💰
Description
Description of the procurement:
“Works include WC upgrades, accessibility improvements, storage works, door automation, and resurfacing works at St Brigid’s Community Centre, Ballintra, Co. Donegal.”
Description of the procurement
Works include WC upgrades, accessibility improvements, storage works, door automation, and resurfacing works at St Brigid’s Community Centre, Ballintra, Co. Donegal.
Show more
Main site or place of performance:
“The contract will be performed at St Brigid’s Community Centre, Lisminton, Ballintra, Co. Donegal, Ireland.
The works include WC refurbishments,...”
Main site or place of performance
The contract will be performed at St Brigid’s Community Centre, Lisminton, Ballintra, Co. Donegal, Ireland.
The works include WC refurbishments, accessibility upgrades, construction of new storage rooms, installation of office storage units, door automation, and resurfacing of the basketball court and meeting room as described in the tender documents.
Show more
Duration: 4 (MONTH)
The time frame below is expressed in number of months.
Information about variants
Variants will be accepted ✅ Award criteria
Criterion:
“The Tenderer shall submit a detailed programme showing sequencing, duration of works, key milestones and completion date. Assessment will be based on...”
Criterion
The Tenderer shall submit a detailed programme showing sequencing, duration of works, key milestones and completion date. Assessment will be based on completeness, realism, risk‑management and ability to meet grant deadlines
Show more Title
Lot Identification Number: LOT-0001
Procedure Type of procedure
Open procedure ✅ Administrative information
Time limit for receipt of tenders or requests to participate: 2026-02-27 00:00:00 📅
Languages in which tenders or requests to participate may be submitted: English 🗣️
Minimum time frame during which the tenderer must maintain the tender: 60
Complementary information Review body
Name: The High Court of Ireland
National registration number: The High Court of Ireland
Postal address: Four Courts, Inns Quay, Dublin 7
Postal code: D07 WDX8
Postal town: Dublin
Region: Dublin🏙️
Country: Ireland 🇮🇪
E-mail: highcourtcentraloffice@courts.ie📧
Phone: +353 1 8886000📞 Service from which information about the review procedure may be obtained
Name: The High Court of Ireland
National registration number: The High Court of Ireland
Postal address: Four Courts, Inns Quay, Dublin 7
Postal code: D07 WDX8
Postal town: Dublin
Region: Dublin🏙️
Country: Ireland 🇮🇪
E-mail: highcourtcentraloffice@courts.ie📧
Phone: +353 1 8886000📞
Source: OJS 2026/S 023-078816 (2026-02-02)