RTÉ MV Switchgear
Raidio Teilifis Eireann (RTE)
RTÉ has a requirement to upgrade its existing TV Block medium voltage switchgear at its Donnybrook site. As part of this upgrade, it is planned to replace the existing MV switchboard as detailed in this tender document. This turnkey project incorporates both Civil and M&E works. A single contractor will be awarded this turnkey project and will be responsible for the Project Management of the project from Contract Award to Practical Completion.
DeadlineThe time limit for receipt of tenders was 2021-02-26. The procurement was published on 2021-01-19.
SuppliersThe following suppliers are mentioned in award decisions or other procurement documents:
Who? What?- • Electrical installation work of heating and other electrical building-equipment › Medium-voltage installation work
- • Low- and medium-voltage cable › Medium-voltage cable
- • Medium-voltage equipment › Medium-voltage panels
- • Miscellaneous engineering services › Mechanical and electrical engineering services
Procurement history
| Date | Document |
|---|---|
| 2021-01-19 | Contract notice |
| 2021-05-13 | Contract award notice |
Contract notice (2021-01-19)
Object
Scope of the procurement
Title: Medium-voltage equipment
Reference number: 20P048
Short description:
Notice metadata
Original language: English 🗣️
Document type: Contract notice
Nature of contract: Supplies
Regulation: European Union, with participation of GPA countries
Common procurement vocabulary (CPV)
Code: Medium-voltage equipment 📦
Additional CPV: Low- and medium-voltage cable 📦
Place of performance
NUTS region: Éire/Ireland 🏙️
Procedure
Procedure type: Open procedure
Type of bid: Submission for all lots
Award criteria
The most economic tender
Contracting authority
Identity
Country: Ireland 🇮🇪
Awarding authority type: Body governed by public law
Awarding authority name: Raidió Teilifís Éireann (RTÉ)
Postal address: Donnybrook, Co. Dublin
Postal town: Dublin
Contact
Internet address: http://www.rte.ie 🌏
E-mail: mark.carron@rte.ie 📧
Phone: +353 12083373 📞
URL for documents: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
URL for participation: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
Reference
Dates
Date dispatched: 2021-01-19 📅
Submission deadline: 2021-02-26 📅
Publication date: 2021-01-22 📅
Identifiers
Notice number: 2021/S 015-030768
OJ-S issue: 15
Object
Scope of the procurement
Estimated total value: 500 000 EUR 💰
Estimated value excluding VAT: 500 000 EUR 💰
Duration: 6 months
Place of performance
Main site or place of performance: RTÉ Donnybrook.
Procedure
Legal basis: 32014L0024
Time of receipt of tenders: 13:00
Languages in which tenders or requests to participate may be submitted: English 🗣️
Tender opening date: 2021-02-26 📅
Tender opening time: 13:00
Contracting authority
Identity
National registration number: 8T50578M
Contact
Contact point: Mark Carron
Address of the buyer profile: https://irl.eu-supply.com/ctm/Company/CompanyInformation/Index/396 🌏
Documents URL: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
Complementary information
Review body
Name: The Courts Service
Postal address: 15 - 24 Phoenix Street
Postal town: Smithfield
Country: Ireland 🇮🇪
Source: OJS 2021/S 015-030768 (2021-01-19)
Object
Scope of the procurement
Title: Medium-voltage equipment
Reference number: 20P048
Short description:
RTÉ has a requirement to upgrade its existing TV Block medium voltage switchgear at its Donnybrook site. As part of this upgrade, it is planned to replace the existing MV switchboard as detailed in this tender document. This turnkey project incorporates both Civil and M&E works. A single contractor will be awarded this turnkey project and will be responsible for the Project Management of the project from Contract Award to Practical Completion.
Show more
Original language: English 🗣️
Document type: Contract notice
Nature of contract: Supplies
Regulation: European Union, with participation of GPA countries
Common procurement vocabulary (CPV)
Code: Medium-voltage equipment 📦
Additional CPV: Low- and medium-voltage cable 📦
Place of performance
NUTS region: Éire/Ireland 🏙️
Procedure
Procedure type: Open procedure
Type of bid: Submission for all lots
Award criteria
The most economic tender
Contracting authority
Identity
Country: Ireland 🇮🇪
Awarding authority type: Body governed by public law
Awarding authority name: Raidió Teilifís Éireann (RTÉ)
Postal address: Donnybrook, Co. Dublin
Postal town: Dublin
Contact
Internet address: http://www.rte.ie 🌏
E-mail: mark.carron@rte.ie 📧
Phone: +353 12083373 📞
URL for documents: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
URL for participation: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
Reference
Dates
Date dispatched: 2021-01-19 📅
Submission deadline: 2021-02-26 📅
Publication date: 2021-01-22 📅
Identifiers
Notice number: 2021/S 015-030768
OJ-S issue: 15
Object
Scope of the procurement
Estimated total value: 500 000 EUR 💰
Estimated value excluding VAT: 500 000 EUR 💰
Duration: 6 months
Place of performance
Main site or place of performance: RTÉ Donnybrook.
Procedure
Legal basis: 32014L0024
Time of receipt of tenders: 13:00
Languages in which tenders or requests to participate may be submitted: English 🗣️
Tender opening date: 2021-02-26 📅
Tender opening time: 13:00
Contracting authority
Identity
National registration number: 8T50578M
Contact
Contact point: Mark Carron
Address of the buyer profile: https://irl.eu-supply.com/ctm/Company/CompanyInformation/Index/396 🌏
Documents URL: http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE 🌏
Complementary information
Review body
Name: The Courts Service
Postal address: 15 - 24 Phoenix Street
Postal town: Smithfield
Country: Ireland 🇮🇪
Source: OJS 2021/S 015-030768 (2021-01-19)
Contract award notice (2021-05-13)
Object
Notice metadata
Document type: Contract award notice
Procedure
Type of bid: Not applicable
Contracting authority
Identity
Postal address: Donnybrook
Postal code: Co. Dublin
Reference
Dates
Date dispatched: 2021-05-13 📅
Publication date: 2021-05-18 📅
Identifiers
Notice number: 2021/S 095-249230
Refers to notice: 2021/S 015-030768
OJ-S issue: 95
Procedure
Award criteria
Quality criterion (name): Technical design and suitability
Quality criterion (weighting): 20 %
Quality criterion (name): Project methodology
Quality criterion (weighting): 10 %
Quality criterion (name): Impact on and disruption to existing services
Quality criterion (weighting): 5 %
Quality criterion (name): Key personnel and team structure
Delivery
Sustainability impact
Value added dimensions and innovation
Health and safety
Quality standards
Price (weighting): 35 %
Award of contract
Date of contract conclusion: 2021-05-11 📅
Name: CJK Engineering
National registration number: 8284823F
Postal address: Unit 1 The Business Centre, Stadium Business Park
Postal town: Dublin
Postal code: Dublin 11
Country: Ireland 🇮🇪
Phone: +353 18829700 📞
E-mail: aidan@cjkengineering.ie 📧
Internet address: http://www.cjkengineering.ie 🌏
Information about tenders
Number of tenders received: 3
Complementary information
Review body
Postal address: 15 — 24 Phoenix Street
Source: OJS 2021/S 095-249230 (2021-05-13)
Object
Notice metadata
Document type: Contract award notice
Procedure
Type of bid: Not applicable
Contracting authority
Identity
Postal address: Donnybrook
Postal code: Co. Dublin
Reference
Dates
Date dispatched: 2021-05-13 📅
Publication date: 2021-05-18 📅
Identifiers
Notice number: 2021/S 095-249230
Refers to notice: 2021/S 015-030768
OJ-S issue: 95
Procedure
Award criteria
Quality criterion (name): Technical design and suitability
Quality criterion (weighting): 20 %
Quality criterion (name): Project methodology
Quality criterion (weighting): 10 %
Quality criterion (name): Impact on and disruption to existing services
Quality criterion (weighting): 5 %
Quality criterion (name): Key personnel and team structure
Delivery
Sustainability impact
Value added dimensions and innovation
Health and safety
Quality standards
Price (weighting): 35 %
Award of contract
Date of contract conclusion: 2021-05-11 📅
Name: CJK Engineering
National registration number: 8284823F
Postal address: Unit 1 The Business Centre, Stadium Business Park
Postal town: Dublin
Postal code: Dublin 11
Country: Ireland 🇮🇪
Phone: +353 18829700 📞
E-mail: aidan@cjkengineering.ie 📧
Internet address: http://www.cjkengineering.ie 🌏
Information about tenders
Number of tenders received: 3
Complementary information
Review body
Postal address: 15 — 24 Phoenix Street
Source: OJS 2021/S 095-249230 (2021-05-13)
New procurements in related categories 🆕